国外某工程2×220mw火电厂epc总承包合同

《国外某工程2×220mw火电厂epc总承包合同》由会员上传分享，免费在线阅读，更多相关内容在工程资料-天天文库。

1、某国外工程EPC合同2APPENDIX2CONTRACTDATASHEET附件2合同数据表NameofContract:EPCContractonXX2×220MWThermalPowerPlant合同名称:XX2×220MW火电厂EPC总承包合同ContractNo.合同号：____________________________________ClauseRef.参考条款Data数据GC1Owner业主Contractor总承包商Conciliator(s)仲裁者Name:GC1TimecompletionPlantfor:电厂竣

2、工时间-UnitNo.1:36(thirtysix)monthsfromeffectivedateofContract.1号机组：从合同生效之日起36个月；-UnitNo.2andthewholePlant:42(fortytwo)monthsfromeffectivedateofContract.2号机组及整个电厂：从合同生效之日起42个月；GC4ContactsforNoticePurposes:联系：YYHeadquarters:64/64GC5TheGoverningLaw适用法律:GoverningLawshallbethe

3、LawoftheSocialistRepublicofVietnam.TheContractorshallperformtheContractstrictlyincompliancewiththeLawofVietnam.ClaimsreferringtoSettlementoftheDisputes(ifany)arisingduringtheContract’sperformanceshallbegovernedbythelawsissuedandin-useintheSocialistRepublicofVietnam.合同适用

4、的法律是某国社会主义共和国的法律。承包商应该严格遵循某国法律执行合同。如果在合同执行工程中出现争执，由某国社会主义共和国的现行法律来处置争执。GC8.1ContractorshallcommenceworkontheXXCoal-firedThermalPowerPlantrightaftertheEffectiveDate承包商应该在合同生效之日起，开始执行XX燃煤火电厂总包合同。TheContractshallenterintofullforceandbecomeeffectiveonthedatewhenallofthefoll

5、owingconditionshavebeenfulfilled:以下条件满足后，合同才能全面生效：1)thisContractAgreementhasbeensignedforandonbehalfofYYandtheContractor;YY集团和承包商代表签署合同协议。2)TheBidderhassubmittedtoYYthePerformanceSecurityandAdvancePaymentGuarantee；投标商向YY集团支付履约保函和预付款保函。3)TheBidderhasreceivedtheAdvancePay

6、mentfromYYinaccordancewithrelevanttermsoftheContract.投标商根据合同条款的规定，从YY集团收到预付款。GC11.2Thepriceshallbefixed合同总价固定GC13.3AmountofPerformanceBondis10%ofContractprice履约保函是合同总价格的10%GC25.2.2PeriodduringwhichtheGuaranteeTestshouldbeconductedfollowingcommissioning:firsttestbeforeRe

7、liabilityRun,secondandthirdtestbetweenstartReliabilityRunandwithin3monthsafterPAC.性能实验在调试后进行：第一次在可靠性运行前进行，第二次和第三次（如有）在可靠性运行开始至PAC后三个月期间。64/64GC26.2`LiquidatedDamagesfordelayinTimeforCompletionofeachUnitofXXPowerPlantwillbe120,000USD/dayofdelayforeachunitfromtheguarantee

8、dDateofCompletionorfromthedateresultingfromanExtensionofTimeforCompletiongrantedinaccordancewithGC39,uptoamaxi